Carlin v. Cavender

Wagner, Judge,

delivered the opinion of the court.

This was an action on a special tax bill issued by the city engineer of the city of St. Louis, to defray the cost of improving Lucas Avenue in front of the property of the defendant. Two objections were made in the answer; first, that the special ordinance numbered 6540, which directed the work to *288 be done was invalid ; and, secondly, that the work was done by the plaintiff after the date fixed by the contract for its completion.

Ordinance 6510, ordering the woi'k to be done, authorized the city engineer to cause Lucas Avenue from Compton Avenue to Ware Avenue to be graded, curbed, guttered, macadamized and the cross-walks and the side-walks to be paved. When' this ordinance was passed, the charter gave the City Council “power to cause the construction, reconstruction and repairs of all streets, alleys and public highways within the city at such time and to such extent and of such dimensions and material, and in such manner and under such general regulations, as shall be provided by ordinance.” (Sess. Acts 1867, p. 73, § 9.) At the time the work was let out and the contract was performed, there was a general ordinance prescribing the size and character of the materials and the kind of materials'to be used, and there is no point made in that respect, but the question is now raised that the time, extent and dimensions of the work are nowhere prescribed or fixed by the ordinance.

So far as the time is concerned in which the work was to be done, we think the ordinance is sufficiently explicit. The engineer is authorized and instructed to cause the work to be done. This conferred on him a present authority. By no fair construction is there any requirement for stating the precise day when the work should be commenced, or within what period it should be finished.

The extent is clearly designated. It is to improve the entire street, from Compton Avenue to Ware Avenue, and the dimensions and materials are prescribed in the amendatory ordinance 6962, which declares that the material to be used for the curbing, guttering, macadamizing and cross-walks shall be of good sound limestone, and such as the vicinity of the city of St. Louis produces, and the side-walks shall be paved with good, hard-burned, red brick, commonly called paving brick; and they are also prescribed in the general ordinance in reference to the engineer department, which sets *289 out the size and dimensions of the material, and the manner in which it shall be laid down and used. A fair and just construction of the ordinances and charter fully warranted the action of the city and its officers.

There is obviously no merit in the point that the work was not completed within the time limited by the contract. There is nothing to show that time was of the essence of the contract. For prudential reasons the engineer suspended the work for a time and the contractors assented to that suspension,, but when it was deemed advisable to proceed the work was then completed and received. It does not appear that the defendant suffered any injury by the delay. The trial seems to have been in all things fair and unexceptionable, but there is an error in the judgment.

The court rendered a personal judgment against the defendant and also a special judgment against the property. Under the decisions of this court no general or personal judgment could be rendered, and that part of the judgment therefore will be reversed and the special judgment will be affirmed.

The other judges concur.