Campbell v. Rock Oil Co.

1. Mines and Minerals—Oil and Gas Leases—Bigut of Lessor to Terminate. In a suit by a lessor to terminate the lessee’s privilege of exploration under an oil and gas lease, which under the law of Indiana could be terminated at the end of any year, and prior to the finding of oil or gas in paying quantities, only by the giving of notice a reasonable time before the expiration of such year, the burden rests upon the complainant to prove that the time between the giving of the notice and the expiration of the year was a reasonable time within which to ascertain whether oil or gas in paying quantities could be found. 2. Same—Estoppel. Where the noiice given by a lessor in an oil and gas lease of an intention to terminate the lessee’s privilege of exploration thereunder at the end of a year, because of delay in operating, required the lessee to “proceed with all reasonable speed and promptness,” under penalty óf a forfeiture of all of its rights, and at the end of the year the lessee was so proceeding and had completed a well, but, owing to an inflow of salt water, it became necessary to Incur large expense for machinery and pumping to render the well productive, which expenditure was made with the knowledge of the lessor, she was estopped to thereafter claim that the lease was terminated by the notice.

Appeal from the Circuit Court of the United States for the District of Indiana. The court on final hearing sustained the master’s report; and appellant’s bill for the annulment of a gas and oil lease was dismissed for want of equity. The lease is as follows: “This agreement made and entered into this 20th day of May, A. D. 1897, by and between Julia E. Campbell and Chas. J. Campbell, of the County of Cook, and State of Illinois, of the first part, and Bock Oil Co. of the second part, wituesseth: “That the said parties of the first part, for and in consideration of the agreements hereinafter mentioned, have granted, demised and let unto the party of the second part for the purpose and with the exclusive right of drilling and operating for petroleum and gas, all that certain tract of land situated in township, Liberty, county, Delaware, and state of Indiana, bounded and described as follows to-wit: “Being in section number 35, township number 21, range number 11 East, bounded north by lands of Margaret J. Murray, and Jno. Shrayer, east by lands of Mary R. Sparks, south by lands of W. C. Swanders and H. B. Swanders. west' by lands of Geo. T. .Orr, containing 120 acres, be the same more or less, together with the right of way over said premises to the places of operat.ing, the right to lay pipes to convey water, oil and gas, and the right to remove any machinery or fixtures placed on skid premises by the party of the second part. “The party of the second part is to have and to hold the said premises for and during the term of five years from the date hereof, and as much longer as oil or gas are found in paying quantities or the rental paid thereon. “The said first parties shall fully use and enjoy said premises for farming purposes, except such parts as may be necessary for said operations. “In consideration of said grant and demise, the said party of the second part agrees to give or pay to the said parties of the first part, the full equal 1-6 part of all the oil produced or saved from the premises, and to deliver the same, free of expense, into tanks or pipe lines to the credit of the first parties. “If gas only, is found the party of the second part agrees to pay to the parties of the first part fifty ($50) dollars per year for the product of each well while the same is used off the premises. “It is agreed that the first parties may have gas free of cost for household use on the premises so long as this lease is in force; and there shall be no wells drilled within 300 feet of the buildings now on the premises, without consent of the first parlies. “It is further agreed, that the party of the second part shall complete a well on the described premises, within one year from the date above, or in default thereof pay to the parties of the first part for such delay a yearly rental of $60.00 on the said premises from the time of completing such well, as above specified, until such well shall be completed. The said yearly rental shall be deposited to the credit of the parties of the first part in the Citizens’ Bank, Muncie, Indiana, or be paid direct to first parties. And a failure to complete such well, or to pay said rental shall render this lease null and void. The party of the second part agrees to drill an oil or gas well within one year from the above date or forfeit to the parties of the first part fifty ($50) dollars. The party of the second part agrees to pay rental on all lands at rate of 50 cents per acre, as above described, excepting forty (40) acres for each well drilled, or abandon same. “Party of the second part agrees to pay a reasonable damage done fences, growing crops, and timber, while operating. “All rentals shall be paid annually on or before July 1st. “It is understood between the parties of this agreement, that all the conditions between the parties hereunto shall extend to their heirs, executors and assigns.” No well was drilled prior to 1904; but the stipulated rental was paid each year, including a payment before July 1,1903, for the year ending May 20,1904. On March 26, 1904, appellant served upon appellees the following notice: “You are hereby notified that the lease for gas and oil made by the undersigned to the Rock Oil Company, bearing date May 20th, 1897, on the following described real estate in Delaware county, state of Indiana, to wit: The west one half (%) of the south-west one quarter G4) of section 35, township 21, range 11, east, and west one half (y2) of east one half (,y2) of southwest one quarter (%) of section 35, township 21, range 11 east, containing 120 acres, will not be extended beyond the period for which extension has been made and assented to, to wit: May 20th, 1904; or delay in operations on said premises be delayed beyond such period; nor will a money consideration be received and accepted for further extension or delay in operation thereon. “You are hereby notified and required to proceed with all reasonable promptness and dispatch to operate for oil and gas on said premises under penalty of forfeiture of all rights and privileges under said instrument of lease.” After the middle of April, 1904, appellees began to''drill.' They went to a depth of 1,240 feet. Oil-bearing rock was found at 955 feet. It was penetrated 285 feet. This was a proper depth for finding oil in that territory. On May 18th the well was completed and was shot. It was cleaned out on the 19th, and the pumps wore started. Only water came. On the 20th and for some days thereafter small quantities of oil were obtained, when suddenly large volumes of salt water prevented the well from producing oil. The pumps were kept working day and night “until some time after the commencement of this suit,” on June 10th. During this time appellees in good faith tried to produce oil, and they operated skillfully in an endeavor to ascertain whether the well could be made a paying one or not. A well in that territory at that time could be drilled, shot, and equipped for pumping in from 15 to 25 days; and contractors, whose terms were reasonable, were available to appellees. In their operations on appellant’s land appellees expended $1,677 before May 20th; and after that date, $$,704, of which the sum of $1,551 was for machinery, which they subsequently removed. Appellant had full knowledge of appellees’ operations, both before and aftr ér May 20th, and made no objection whatever prior to beginning this suit.